Welcome to Ansari Steel. These Terms and Conditions govern your use of our website and services. By accessing our website or using our services, you agree to comply with these terms. If you do not agree, please do not use our website or services.

Use of Website

The content on this website is provided for general information about our CNC fiber laser cutting, metal fabrication, welding, and sheet metal services.

You agree not to:
Use the website for unlawful purposes
Attempt to gain unauthorized access to the website or server
Copy, reproduce, or distribute website content without permission

We reserve the right to modify or discontinue any part of the website without notice.

Services and Quotations

All service descriptions provided on the website are for informational purposes only.

Quotations provided by Ansari Steel:
Are based on project details shared by the client
May vary if specifications, materials, or quantities change
Are valid for a limited time as mentioned in the quotation

We reserve the right to refuse service if project requirements do not meet safety or legal standards.

Orders and Payments

To begin a project, a partial advance payment may be required.

Payment terms:
Advance payment before production starts
Remaining balance as per agreed milestones or upon completion
Payments must be made through approved methods

Failure to complete payment may result in delay, suspension, or cancellation of the project.

Project Timelines

Project timelines depend on:
Material availability
Project complexity
Design approval
Client response time

While we aim for timely delivery, Ansari Steel is not responsible for delays caused by external factors beyond our control.

Client Responsibilities

Clients are responsible for:
Providing accurate drawings, measurements, and specifications
Approving designs before production
Ensuring timely payments

Ansari Steel is not liable for errors resulting from incorrect information provided by the client.

Quality and Warranty

We strive to maintain high-quality standards in all CNC cutting, fabrication, and welding services.

Any warranty provided will be clearly mentioned in the project agreement.
Normal wear and tear, misuse, or unauthorized modifications are not covered under warranty.

Limitation of Liability

Ansari Steel shall not be liable for:
Indirect or consequential losses
Business interruption
Loss of profits

Our total liability shall not exceed the total amount paid for the specific service in question.

Intellectual Property

All website content including text, images, logos, and designs are the property of Ansari Steel and may not be used without written permission.

Custom designs provided by clients remain the property of the respective client.

Termination

We reserve the right to terminate or suspend services if:
Payment terms are violated
False or misleading information is provided
Terms and Conditions are breached

External Links

Our website may contain links to third-party websites. We are not responsible for their content or policies.

Changes to Terms

We may update these Terms and Conditions at any time. Updated versions will be posted on this page with a revised effective date.

Governing Law

These Terms and Conditions shall be governed by the laws of Pakistan. Any disputes shall be subject to the jurisdiction of the courts of Pakistan.

Contact Information

If you have any questions regarding these Terms and Conditions, please contact:

Ansari Steel
Karachi, Pakistan
+92 335 1760555
[email protected]